Terms and conditions

GENERAL TERMS AND CONDITIONS

of World of Online, s.r.o.

Legal relationships in which World of Online, s.r.o. is a party as a contractor or supplier are governed by these general terms and conditions. The provisions of these general terms and conditions are binding on the parties to the contract concluded orally or in writing between World of Online, s.r.o. and the customer (hereinafter referred to as the “Agreement”).

The provisions of these general terms and conditions are for the parties listed in our offer or written contract (hereinafter referred to as the “Contract”), i.e. for World of Online, s.r.o. and the customer, as binding as the provisions of the Contract.

The Agreement, together with these General Terms and Conditions, sets forth the entire agreement and understanding of the parties in connection with the Work or Services. Any changes or deviations from the Agreement must be in writing and must be signed by authorized representatives of both parties. In the event of a difference between the Agreement and these general terms and conditions, the Agreement is binding.

Any changes to the offer, order, draft of the Contract or its amendment will be considered by the contracting parties as a new offer, order, new draft of the Contract or amendment. The contracting parties apply § 1740 paragraph 3 of Act No. 89/2012 Coll., Civil Code, as amended (hereinafter only

“Civil Code”), they exclude.

Each article or term of the Agreement, general terms and conditions and other annexes (if any) constitutes a separate and independent provision. Should a court or other arbitral body with relevant authority decide on the invalidity or unenforceability of any of the provisions of the Agreement, general terms and conditions and other appendices (if any), the other provisions will continue to remain in full force and effect.

More detailed conditions for creating an internet presentation

The work that is the subject of the Contract will be carried out to the extent specified by the Contract and the Project Documentation (P02), if agreed. In the case of each additional request of the Customer, the Contractor shall discuss with the Customer the possible consequences of the requested change on the completion date and the price of the work and shall make a corresponding record of it.

The textual parts of the presentation, expressing comprehensive information about the Client, are prepared by the Contractor based on the documents provided to him for that purpose by the Client, who is responsible for editorial editing and linguistic and grammatical correctness. The contractor is not responsible for the content, language or grammar level of these documents.

Terms of performance

The performance dates are agreed in the Schedule specified in the Contract.

Fulfillment of the agreed deadlines is conditional on proper and timely cooperation on the part of the Customer according to point 3.

In the event that the Client does not provide the necessary cooperation in a proper and timely manner, while it is clear from its nature that it is necessary for the proper completion of the work, the Contractor is entitled to adequately adjust the performance dates, but always by at least the duration of the Client’s delay.

In the event that the Customer is in delay in providing the necessary cooperation for more than 14 days, the Contractor shall be entitled to an aliquot part of the price for the part of the work completed on

the following one after the 14th day of delay has passed. The Contractor is entitled to issue an invoice to the Customer – a tax document for this part of the work. The amount stated on this invoice will be deducted from the amount of the final invoice – tax document. The Contractor shall further provide the Customer with an additional period for providing cooperation and at the same time instruct him that in the event that the additional period for providing cooperation expires in vain, the Contractor has the right to withdraw from the Contract. The withdrawal takes effect on the day the withdrawal is delivered to the Customer.

Cooperation of the Customer

The Customer undertakes to continuously provide the Contractor with the agreed cooperation, in the following manner: providing work requirements; provision of agreed textual and graphic materials, or other materials needed to fulfill the Contractor’s obligations under the Contract. The documents will be provided according to the Schedule specified in the Contract and according to the Contractor’s requirements without unnecessary delay; providing ongoing consultations and comments. The Customer undertakes to provide, at the request of the Contractor, the necessary information and data regarding the preparation and implementation of the work without undue delay after their request. The contractor is not obliged to check the correctness and completeness of the information provided;

notify the Contractor immediately of all changes and other circumstances related to the execution of the work;

provision of textual, graphic and other documents prepared for the Customer by third parties. The customer is responsible for the quality and compliance with the deadlines for handing over documents;

ensuring access to the Customer’s computer network, applications and data to the extent necessary to fulfill the Contractor’s obligations under this Agreement, provided that this is necessary for the proper performance of the Agreement;

The customer undertakes to specify in advance for which documents he will request their return. The Contractor is not obliged to return documents that have not been clearly specified by the Customer;

approval of partial works submitted to the Customer by the Contractor;